合同模板：中英文工程合同

《合同模板：中英文工程合同》由会员分享，可在线阅读，更多相关《合同模板：中英文工程合同（6页珍藏版）》请在装配图网上搜索。

1、Contract of Construction Project合同编号： Contract Number: 工程名称： Project Name: 发包方（甲方）： 工程设计顾问（北京） Employer (Party A): International Consulting Engineers ( Beijing) Limited 承包方（乙方）： 中寰艺高建筑装饰工程有限公司 Contractor (Party B): Zhong Huanyigao Building Decoration Engineering Co. , Ltd 根据中华人民共和国合同法和建筑安装工程承包合同条例及有

2、关规定，为明确双方在施工过程中的权利、义务和经济责任，经双方协商同意签订本合同。 In order to make definite of the rights, obligations and economic responsibilities of both parties during the construction, the parties, in accordance with The PRC Contract Law and Construction Engineering Contract Regulations and relevant provisions, agree t

3、o sign this contract. 第一条 工程项目Article 1, Project item 1 工程地点： Project site: 2. 工程范围： Scope of project 3. 工程造价：人民币 元整 (该造价为包工包料价) Project cost: PMB Yuan only(Cost of this contract is the contract price for labor and materials) 第二条施工准备 Article 2, Preparation for construction 1 甲方协助乙方办理临时水电及垂直运输,提供建筑图纸

4、及有关隐蔽障碍物的资料。 Party A shall assists party B to deal with the procedures of temporary hydropower and vertical transportation and provide architectural drawings and documents of relevant concealed obstacles . 2 乙方：. Party B: 负责施工区域的临时设施、水电管线的铺设、管理、使用和维修工作； Be responsible for the works of laying, manage

5、ment, use and maintenance of the temporary facilities, water and electricity pipeline in the construction area. 组织施工管理人员和材料、施工机械进场； Organize construction management staff and construction materials, construction machinery enter the Site. 负责在装修期间保持公共地方清洁及每天负责将装物料弃置于由管理处指定的垃圾收集处。 Be responsible for ke

6、eping public places clean during construction and packing construction material and leaving in the garbage collection place designated by management office each day. 第三条工程期限 Article 3 Period of Construction 1. 根据工期和使用需要，商定工程总施工期为 天（日历天），自 年 月 日开工至 年 月 日完工 According to the period of construction and

7、the use need, the total construction period agreed shall be days (Calendar days), start from the date of and complete on the date of . 2 如遇下列情况，经甲方现场代表签证后，工期相应顺延： Construction period shall be prolonged upon Party A site representatives confirmation when the matters occur as follows. 按施工准备规定，甲方未协助乙方办

8、理临时水电及垂直运输,影响进场施工； According to the requirements of construction preparation, Party A fail tot assist Party B to apply for temporary water and electricity and vertical transportation and have an impact on Party B construction; 因甲方提出增减项目而造成重大设计变更，因而影响进度； The material modification or change of design

9、due to the party A s requirement of addition or deletion of project have the effect of hindrance on the progress of works. 未按合同规定拨付预付款、工程款而影响施工； Party A fail to pay the advance payment and construction cost to party B and impact the construction progress; 人力不可抗拒的因素而延误工期。 The delay of schedule of con

10、struction due to Force Majeure. 第4条 工程质量Article 4 The quality of project 1 本工程质量经双方研究要求达到双方约定之验收标准。 The quality of project should achieve the requirements of acceptance agreed by both parties. 2 乙方必须严格按照施工图纸、说明文件和国家颁发的建筑工程规范、规程和标准进行施工，并接受甲方的监督。 Party B should carry on the construction in strict acco

11、rdance with drawing, specification file and regulations and specifications authorized by the competent authorities and be under the supervision of Party A. 3 乙方在施工过程中必须遵守下列规定： Party B should, during the construction, comply with the provisions as follows: 1 由乙方提供给甲方的所有材料必须经甲方同意方可使用，未按要求购买严禁使用； All m

12、aterials provided by Party B should be subject to the approval of Party A prior to use, And none of the same being bought without conformity with Party A requirements can be used. 2 隐蔽工程必须经甲乙双方检查，方可进行下一道工序； The concealed works should be checked by both parties before the next progress; 3 工程竣工后，乙方按规定

13、对工程实行保修，保修时间自通过竣工验收之日算起，保修期一年。 Party B shall take the liability of maintenance following the complete of works. The period of maintenance shall be one year from the day of acceptance of complete. 第5条 工程价款的支付与结算Article 5 Payment and settlement of the contract price 合同总价 50 %, 即 元 The total contract p

14、rice 50%, which is Yuan. 中期款The payment of medium-term 工程进度过半三日内 Within 3 (three) days after the progress more than half. 合同总价 40 %, 即 元 The total contract price 40%, which is Yuan. 尾款Final Payment 竣工验收结算后七日内Within 7 (seven) days after the completion acceptance and settlement. 合同总价 10 %, 即 元The tota

15、l contract price 10%, which is Yuan. 第6条 施工与设计变更Article6 The Modification of Construction and Design 1 乙方交付的设计图纸、说明和有关技术资料，作为施工的有效依据，开工前由甲方组织签字认同，作为施工的补充依据，甲、乙双方均不得擅自修改。 Design drawing, illustration and relevant technical data consigned by party B are the basis for construction and shall be confirme

16、d by party As signature, which is deemed as the supplementary basis and shall be modified by any party without authorization. 2 施工中如发现因甲方要求而发生的设计错误或严重不合理的地方，乙方应及时以书面形式通知甲方，由甲方及时会同乙方等有关单位研究确定修改意见或变更设计文件，乙方按修改或变更的设计文件进行施工。若发生增加费用（包括返工损失、停工、窝工、人员和机构设备调迁、材料构配件积压的实际损失）由甲方负责，并调整合同造价。 If and when any error

17、 or material unreasonable problem of design due to party As requirement, Party B shall notify Party A promptly in writing and decide the amendment or modification of the design documentation by the consultation and negotiation between parties and units concerned. Party B shall carry out construction

18、 according to the design documents modified or changed. If project cost increase (including the actual loss of rework loss, stoppage or slowdown, personnel and machine equipment relocated, material structures, fixtures backlog), shall be responsibility by Party A, and be adjusted the contract price

19、together with Party B. 3 乙方在保证工程质量和不降低设计标准的前提下，提出修改设计、修改工艺的合理化建议，经甲方、设计单位或有关技术部门同意后采取实施。 Any reasonable suggestion on the modifications of design and craft proposed by Party B, subject to the quality and without reducing standards of design, could be carried out upon the approval of Party A, design

20、unit or concerned technical department. 4 甲方如需设计变更，必须作出正式修改通知书和修改图纸，乙方才予实施。重大修改和增加造价时，必须另行协商，乙方才予实施。 Party A should, if any necessary design change, make the formal amendment and modify drawings for Party Bs implementation. Material changes and cost increased must be negotiated by both parties befor

21、e Party B implement the same. 第7条 工程验收Article 7 Acceptance of project 1 工程施工中地下工程、结构工程必须具有隐蔽验收签证、试水、抗渗等验收合格记录。甲方须及时办理验收签订手续。 The underground engineering, structural engineering in the construction of project should be checked and with issue of certificate and the record of acceptance of water test,

22、anti-permeability and so on. Party A should deal with the acceptance signed formalities timely. 2 工程竣工验收后，甲方才可使用Party A can use the project after completion acceptance 在规定的保修期内，凡因施工造成的质量缺陷应由乙方无偿保修。其保修条件、范围和期限按城乡建设环境保护部（84）城建字第79号通知印发的建筑工程保修办法（试行）执行。 In the provision warranty period, any construction

23、 quality defects, Party B should make maintenance free of the quality defect due to construction, the scope and duration carry out according to the issuance of Cheng Jian No. 79 notification Construction engineering guarantee measures (Trial) by Urban and Rural Construction and Environmental Protect

24、ion Department (84). 第8条 违约责任Article 8 Liability for breach of contract 乙方的责任：Responsibility of Party B: 1 工程质量不符合合同规定的，负责无偿修理和返工。 Take charge of gratis repair and rework if project quality doesnt meet contacts stipulation 2 工程不能按合同规定的工期交付使用的，按合同中关于建设工期提交或拖后的奖罚规定偿付逾期罚款。 If fail to deliver the constr

25、uction according to the contract on time, The overdue fines according to punishment or award of the provision concerning the delivery or delay. 甲方的责任：The responsibility of Party A: 1 未能按照合同的规定履行自己应负的责任，除竣工日期得以顺延外，还应赔偿乙方由此造成的实际损失。 Failed to fulfill their responsibilities in accordance with the provis

26、ions of the contract, in addition to the completion date to be postponed should be compensation for the actual loss of Party B . 2 工程中途停建、缓建或由于设计变更以及设计错误造成的返工，应采取措施弥补或减少损失。同时，赔偿乙方由此造成的停工、窝工、返工、倒运、人员和机械设备调迁、材料和构件积压的实际损失。 The ongoing project is stopped, postponed or due to design changes and rework ca

27、used by design errors, should take measures to remedy or reduce losses. At the same time, compensate Party B the actual loss of work stoppage, slowdown, re-dispatch rework, reshipment, staff and mechanical equipment relocating, the backlog of materials and components. 第9条 纠纷解决办法Article 9 Dispute set

28、tlement 任何一方违反合同规定，双方协商不成，均可向北京仲裁委员会申请仲裁。 Either party could, if any partys breach and fail to negotiation, submit the application of arbitration to the Beijing Arbitration Committee 第10条 附则Article 10 Supplementary 一本合同一式贰份，甲乙双方各执正本一份。 This contract is execute in two counterparts, each party holds a

29、 single original. 2 本合同自双方代表签字，加盖双方公章或合同专用章即生效。工程竣工验收符合要求，待保修期满后合同终止。 The contract becomes effective after signing and sealing by both parties on this foregoing date. The project final acceptance meet the requirements, after the expiry of warranty, ends the contract. 甲方（盖章）：Party A (seal): 乙方（盖章）： Party B (seal): 委托代理人（签章）：Agent 委托代理人（签章）：Agent 电话：Tel: 电话：Tel: 日期：Date: 日期：Date: